�
NOM ET ADRESSE
OFFICIELS DE L�ORGANISME ACHETEUR PUBLIC
Coulommiers
TEXTE L�GAL DE
L�APPEL D�OFFRE (MARCH� PUBLIC)
Coulommiers
Travaux de raccordement au réseau géothermie des installations
d'eau chaude sanitaire et de chauffage, ainsi que des travaux divers concernant
les logements du 13ème groupe du quartier de Vaux appartenant au
patrimoine de l'office public de l'habitat de Coulommiers
Procédure adaptée
7237608201 - SF
Nom et adresse
officiels de l'organisme acheteur : OPH de Coulommiers.
Correspondant : Marie-José THOURET, 13,
allée de La Rotonde, 77120 Coulommiers, tél. : 01 64 03 89 34,
courriel : marches@ophcoulommiers.fr
Adresse internet : http://oph-coulommiers.e-marchespublics.com< ;/span>
Adresse internet du profil d'acheteur :
http://oph-coulommiers.e-marchespublics.com< ;/span>
Principales activités du pouvoir adjudicateur : logement et
équipements collectifs.
Objet du marché : travaux de raccordement au réseau
géothermie des installations d'eau chaude sanitaire et de chauffage,
ainsi que des travaux divers concernant les logements du 13ème groupe du
quartier de Vaux appartenant au patrimoine de l'office public de l'habitat de
Coulommiers.
Type de marché de travaux : exécution.
CPV - objet principal : 45321000.
Lieu d'exécution : 13ème groupe du quartier de Vaux,
77120 Coulommiers.
L'avis implique un marché public.
Estimation de la valeur (H.T.) : 3 600 000 euros.
Des variantes seront-elles prises en compte : oui.
La procédure d'achat du présent avis est couverte par l'accord sur
les marchés publics de l'OMC: oui.
Prestations divisées en lots : oui.
Possibilité de présenter une offre pour un seul lot.
Durée du marché ou délai d'exécution : 7
mois à compter de la notification du marché.
Modalités essentielles de financement et de paiement et/ou
références aux textes qui les réglementent : les
travaux objet du présent marché sont financés par un emprunt,
des subventions, ainsi que les fonds propres de l'OPH.
Langues pouvant être utilisées dans l'offre ou la candidature
: français.
Unité monétaire utilisée, l'euro.
Conditions de participation : conformément à l'article
7 du RC.
La transmission et la vérification des documents de candidatures peut
être
effectuée par le dispositif Marché public simplifié sur
présentation du numéro de
SIRET : non.
Critères d'attribution : offre économiquement la plus
avantageuse appréciée en fonction des critères
énoncés dans le cahier des charges (règlement de la
consultation, lettre d'invitation ou document descriptif).
Type de procédure : procédure adaptée.
Date limite de réception des offres : 8 janvier 2021 à
12 h 00.
Délai minimum de validité des offres : 120 jours
à compter de la date limite de réception des offres.
Autres renseignements : numéro de référence
attribué au marché par le pouvoir adjudicateur / l'entité
adjudicatrice : 2020-24.
Renseignements complémentaires : la présente
consultation, lancée initialement en corps d'état
séparés (lots n�1 à 6) sous forme de procédure
adaptée, concerne la dévolution du sous-lot n�1-2 : Isolation
thermique par l'extérieur Chanvre du lot n� 1 : Isolation thermique par
l'extérieur - Peinture.
Conditions et mode de paiement pour obtenir les documents contractuels et
additionnels :http://www.e-marchespublics.com< " rel="nofollow"
target="_blank">www.e-marchespublics.com< ;/span>
Date d'envoi du présent avis à la publication : 6
novembre 2020.
Adresse auprès de laquelle des renseignements d'ordre technique
peuvent être obtenus : ALTEREA.
Correspondant : François DE MONTGOLFIER, 23, avenue d'Italie,
75013 Paris, tél. : 01 46 28 31 89, courriel : fdemontgolfier@alterea.fr
Adresse auprès de laquelle des renseignements d'ordre administratif
peuvent être obtenus : Office Public de l'Habitat.
Correspondant : Angélique DUMORTIER, 13, allée de La
Rotonde, quartier de Vaux, BP 70003, 77521 Coulommiers cedex, tél. : 01
64 03 89 34, courriel :
marches@ophcoulommiers.fr
Adresse internet : http://www.e-marchespublics.com< ;/span>
Instance chargée des procédures de recours : Tribunal
administratif de Melun, 43, rue du,Général-de-Gaulle, 77000 Melun,
tél. : 01 60 56 66 30, télécopieur : 01.60.56.66.10.
Renseignements relatifs aux lots :
Lot n�1: 1-2. - Isolation thermique par l'extérieur Chanvre.
ITE Chanvre :
Mots descripteurs : Isolation.
CPV - objet principal : 45321000.
Disclaimer
: Below text is machine translated. For accuracy refer the
original language text given above.
�
Public invitation to tender: national
�
Release date :
�
Closing Date : 01/08/2021
�
�
o
Location: 77 - Seine-et-Marne
(�le-de-France)
o AAPC
o works
o Procedure: adapted
�
Industry: Other
Coulommiers
Coulommiers
Connection works to the geothermal network of domestic hot water and heating
installations, as well as various works concerning the housing of the 13th
group of the Vaux district belonging to the heritage of the public housing
office of Coulommiers
Adapted procedure
7237608201
- SF Official
name and address of the purchasing organization: OPH
de Coulommiers. Correspondent: Marie-Jos�
THOURET, 13, all�e de La Rotonde, 77120 Coulommiers, tel. :
01 64 03 89 34, email:
marches@ophcoulommiers.fr
Internet
address : http://oph-coulommiers.e-marchespublics.com <; / span>
Internet address of the buyer
profile:
http://oph-coulommiers.e-marchespublics.com
<; / span>
Main
activities of the contracting authority: housing and
community facilities.
Subject
of the contract: connection works to the geothermal
network of domestic hot water and heating installations, as well as various
works concerning the housing of the 13th group of the Vaux district belonging
to the heritage of the public housing office of Coulommiers .
Type
of works contract: execution.
CPV
- main object: 45321000.
Place
of execution: 13th group of the district of Vaux, 77120
Coulommiers.
The notice involves a public
market.
Estimated
value (excluding VAT): 3,600,000 euros.
Will
variations be taken into account:Yes.
The procurement procedure for
this notice is covered by the WTO Agreement on Government Procurement: yes.
Services divided into lots: yes.
Possibility to present an offer
for a single lot.
Duration
of the market or time limit for completion: 7 months from
the notification of the market.
Main
terms of financing and payment and / or references to the texts which regulate
them: the works covered by this contract are financed by a
loan, subsidies, as well as the own funds of the OPH.
Languages
that can be used in the offer or application: French.
Currency
unit used, the euro.
Conditions
of participation: cin
accordance with article 7 of the LR.
The transmission and
verification of application documents can be
carried out by the Simplified Public Market system on presentation of the
SIRET number : no.
Award criteria: economically
most advantageous tender assessed according to the criteria set out in the
specifications (consultation rules, invitation letter or descriptive document).
Type of procedure: adapted
procedure.
Deadline for receipt of tenders: January
8, 2021 at 12 noon.
Minimum validity period for tenders: 120
days from the final date for receipt of tenders.
Other information: nReference
number attributed to the contract by the contracting authority / contracting
entity: 2020-24.
Additional
information: this consultation, initially launched in
separate trades (lots 1 to 6) in the form of an adapted procedure, concerns the
devolution of sub-lot no.1-2: Thermal insulation from the outside Chanvre du
lot n � 1: Thermal insulation from the outside - Painting.
Conditions
and method of payment to obtain contractual and additional documents:http://www.e-marchespublics.com
<"rel =" nofollow "target =" _ blank ">
www.e-marchespublics.com <; / span>
Date
of dispatch of this notice to publication: November 6,
2020.
Address
from which technical information can be obtained be obtained: ALTEREA
Correspondent: Fran�ois
DE MONTGOLFIER, 23, avenue d'Italie, 75013 Paris, tel .: 01 46 28 31 89, email:fdemontgolfier@alterea.fr
Address
from which administrative information can be obtained: Office
Public de l'Habitat.
Correspondent: Ang�lique
DUMORTIER, 13, all�e de La Rotonde, district of Vaux, BP 70003, 77521
Coulommiers cedex, tel. : 01 64 03 89 34, email:
marches@ophcoulommiers.fr
Internet address : http://www.e-marchespublics.com
<; / span>
Body
responsible for appeal procedures: Administrative Tribunal
of Melun, 43, rue du, G�n�ral-de-Gaulle, 77000 Melun, tel. : 01 60 56 66
30, fax: 01.60.56.66.10.
Information
relating to lots:
Lot
n � 1: 1-2. - Thermal insulation from the outside
Hemp.
ITE Hemp:
Descriptor
words: Insulation.
CPV
- main object: 45321000.